OAR 812-002-0760
Work as a Contractor Includes

“Work as a contractor”, as used in ORS 701.021 (License requirement) includes, but is not limited to:

(1)

Except as modified by section (8) of this rule, construction, alteration, repair, improvement, inspection, set-up, erection, moving, or demolition of a structure or any other improvement to real estate, including activities performed on-site in the normal course of construction, or receiving and accepting any payments for the above.

(2)

Concrete, asphalt and other testing that involves structural modifications, and soils testing associated with planned or existing structures.

(3)

Construction management.

(4)

Excavation, backfill, grading, and trenching for the structure or its appurtenances or to accomplish proper drainage and not for landscaping.

(5)

Improvement of lots with the intent of selling lots with structure(s). This may include contracting with a primary contractor to construct, alter or improve structures.

(6)

Inspection of cross connections and testing of backflow prevention devices performed by persons licensed under ORS 448.279 (Certification of inspectors of cross-connections and testers of backflow assemblies) by the Health Division except when performed by a person licensed as a landscape contracting business as provided under 671.510 (Short title) through 671.710 (Priority on satisfaction of claims) or when performed by an employee of a water supplier as defined in 448.115 (Definitions for ORS 448.115 to 448.285).

(7)

Labor only, regardless of whether compensated by the hour or by the job.

(8)

Pest control, if in the course of that work any structural modifications are performed. Structural modifications do not include the following when performed by a pesticide operator licensed under ORS 634.116 (Pesticide operator license). Installation of soil vapor barriers; sealing of holes, cracks, construction junctures or other small openings that allow the ingress of pests with mortar, plaster, caulking, or similar materials; installation of screens, bird netting and bird repellent devices; installation of rodent shields around utility entrances, doorways and other points of rodent ingress; and drilling of holes equal to or smaller than 3⁄8 inch in diameter for the purpose of injecting insecticides into small voids, removal and replacement of floor tiles for the purpose of drilling a slab floor for the control of subterranean termites; and the drilling of slab floors for control of termites.

(9)

Shoring.

(10)

Shelving attached to a structure.

Source: Rule 812-002-0760 — Work as a Contractor Includes, https://secure.­sos.­state.­or.­us/oard/view.­action?ruleNumber=812-002-0760.

812‑002‑0001
Applicant 812‑002‑0002
Application of Definitions 812‑002‑0011
Administrative Law Judge 812‑002‑0020
Agency 812‑002‑0035
Appeal Committee 812‑002‑0040
Appurtenance 812‑002‑0060
Bid 812‑002‑0080
Board 812‑002‑0120
Casual, Minor or Inconsequential 812‑002‑0140
Complaint 812‑002‑0143
Complainant 812‑002‑0160
Construction Management 812‑002‑0170
Contractor 812‑002‑0180
Contractor Became Aware of the Requirement 812‑002‑0190
Court, Arbitrator or Other Entity 812‑002‑0200
Date the Contractor Becomes Aware of a Lapse in License 812‑002‑0220
Date Contractor Incurred Indebtedness 812‑002‑0230
Days 812‑002‑0250
Direct Contractual Relationship 812‑002‑0260
Dishonest or Fraudulent Conduct 812‑002‑0262
Engaged in the Commercial Harvest of Forest Products 812‑002‑0265
Exercises Management or Supervisory Authority Over the Construction Activities of the Business 812‑002‑0275
Family Members 812‑002‑0280
For Compensation or With the Intent to Sell 812‑002‑0300
Gardener 812‑002‑0320
General Contractor 812‑002‑0325
Good Cause 812‑002‑0345
Hours of Training 812‑002‑0350
Individual 812‑002‑0360
Inspect 812‑002‑0380
Insurance 812‑002‑0390
Key Employee 812‑002‑0400
Labor 812‑002‑0420
Lapse in License 812‑002‑0430
Large Commercial Structure 812‑002‑0440
Last-Known Address of Record 812‑002‑0443
Legal Capacity to Enter into Contracts 812‑002‑0450
Licensee 812‑002‑0460
Monetary Damages 812‑002‑0480
Nature or Complexity 812‑002‑0500
Nurseryman 812‑002‑0520
Occupancy 812‑002‑0530
Office of Administrative Hearings 812‑002‑0533
Officer 812‑002‑0537
Owner 812‑002‑0540
Owner of a Structure 812‑002‑0580
Person 812‑002‑0600
Primary Contractor 812‑002‑0620
Registrant 812‑002‑0630
Reinstate 812‑002‑0635
Reissue 812‑002‑0640
Renewal 812‑002‑0660
Residential Structure 812‑002‑0670
Respondent 812‑002‑0673
Signed by Respondent 812‑002‑0675
Small Commercial Structure 812‑002‑0677
Specialty Contractor 812‑002‑0680
Speculative 812‑002‑0700
Structure 812‑002‑0720
Subcontractor 812‑002‑0740
Substantial Completion 812‑002‑0760
Work as a Contractor Includes 812‑002‑0780
Work as a Contractor Does Not Include 812‑002‑0800
Work Period
Last Updated

Jun. 8, 2021

Rule 812-002-0760’s source at or​.us