OAR 731-007-0280
Waiver of Delay Damages Against Public Policy


Any clause in a Public Improvement Contract purporting to waive, release, or extinguish the rights of a Contractor to damages resulting from ODOT’s unreasonable delay in performing the Contract is void and unenforceable, as against public policy. However, Contract provisions requiring notice of delay, providing for alternative dispute resolution such as arbitration or mediation, providing other procedures for settling Contract disputes, or providing for reasonable liquidated damages, are enforceable.

Source: Rule 731-007-0280 — Waiver of Delay Damages Against Public Policy, https://secure.­sos.­state.­or.­us/oard/view.­action?ruleNumber=731-007-0280.

Last Updated

Jun. 8, 2021

Rule 731-007-0280’s source at or​.us