OAR 812-004-1530
Construction Lien Complaints


(1)

The agency may schedule one or more on-site meetings or telephone mediations among the parties to a construction lien complaint filed under ORS 701.145 (Resolution of complaints involving work on residential structures or certain small commercial structures) for the purpose of discussing settlement of the complaint. Notice of the meeting must comply with OAR 812-004-1450 (On-site Meeting and Telephone Mediation; Attendance of the Complainant)(1). The agency may invite the lienor to participate in the settlement discussions. The on-site meeting may be held on the property of the complainant or another mutually agreeable site. OAR 812-004-1450 (On-site Meeting and Telephone Mediation; Attendance of the Complainant)(2), (3) and (4) apply to an on-site meeting held under this section.

(2)

If the complaint does not settle, the complainant must:

(a)

Join the respondent in an action to foreclose the lien if the lienor has filed such an action; or

(b)

File an action against respondent to recover damages caused by respondent’s failure to pay for material, rental services, labor or subcontractor services that gave rise to the lien.

(3)

The agency will suspend processing the complaint while the complainant complies with section (2) of this rule. If complainant fails, within 60 days from the date of the last on-site meeting or telephone mediation, to comply with section (2) of this rule, the agency may close the complaint. The agency may extend the time to comply with section (2) for good cause.

(4)

While the court action described in section (2) is proceeding, the complainant must comply with OAR 812-004-1520 (Processing of Complaint Based on Judgments and Bureau of Labor and Industries Final Orders).

(5)

If a construction lien complaint involves the same facts and issues as any other open complaint, the agency must process the complaints together.

Source: Rule 812-004-1530 — Construction Lien Complaints, https://secure.­sos.­state.­or.­us/oard/view.­action?ruleNumber=812-004-1530.

812‑004‑1001
Application of Rules
812‑004‑1110
Complaint Processing Fee
812‑004‑1120
Liability of Licensee
812‑004‑1140
Liability of Contractor for Complaint Related to Contractor’s Property
812‑004‑1160
Establishment of Co-Complainant
812‑004‑1180
Complainant’s Responsibility to Pursue Complaint
812‑004‑1195
Exhibits
812‑004‑1210
Address of Complainant and Respondent
812‑004‑1240
Exhaustion of Surety Bond, Letter of Credit or Cash Deposit
812‑004‑1250
Payments From the Bond for Court Costs, Complaint Processing Fee, Interest and Other Costs
812‑004‑1260
Closing a Complaint
812‑004‑1300
Filing Date of Complaint
812‑004‑1320
Jurisdictional Requirements
812‑004‑1340
Form of Complaints, Pre-Complaint Notice
812‑004‑1350
Procedure if Information on Complaint Form is Incomplete
812‑004‑1360
Addition of Complaint Items at On-Site Meeting
812‑004‑1400
Initial Administrative Processing of Complaints
812‑004‑1420
Processing Owner and Primary Contractor Complaints Together
812‑004‑1440
Contracts With Arbitration Agreements
812‑004‑1450
On-site Meeting and Telephone Mediation
812‑004‑1460
Agency Recommendation of Resolution
812‑004‑1480
Resolution by Settlement and Construction of Settlement Agreement
812‑004‑1490
Subsequent On-Site Meetings
812‑004‑1500
Closure of Complaint After Settlement
812‑004‑1505
Complaint Not Settled
812‑004‑1510
Court Judgments, Arbitration Awards and Bureau of Labor and Industries Final Orders
812‑004‑1520
Processing of Complaint Based on Judgments and Bureau of Labor and Industries Final Orders
812‑004‑1530
Construction Lien Complaints
812‑004‑1537
Standards of Care and Workmanship
812‑004‑1600
Payment From Surety Bond, Letter of Credit or Cash Deposit
Last Updated

Jun. 8, 2021

Rule 812-004-1530’s source at or​.us